W00000000 NOTICE TO RECEIVE SEALED BIDS BID #2122-08 The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in …

Posted

W00000000

NOTICE TO RECEIVE SEALED BIDS

BID #2122-08

The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:

WASHINGTON GYM BATHROOM RENOVATIONS

The project includes the construction of a men's and women's bathroom facility in the Washington Gym located at 401 Peters Street in Port St. Joe, FL.

Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be $500.00 per day.

Please place YOUR COMPANY NAME, SEALED BID, and the BID NUMBER on the outside of your envelope and include the original bid, plus 2 copies.

Bids will be received until 4:00 p.m. Eastern Time, on January 21, 2021 at the Gulf County Clerk's Office, 1000 Cecil G. Costin Sr. Blvd, Room 149, Port St. Joe, Florida 32456, and will be opened and read aloud at a meeting of the Board of County Commissioners held in the Donald H. Butler Commission Chamber in the Robert M. Moore Administration Building, Gulf County Courthouse Complex, Port St. Joe, Florida on January 25, 2021 at 9:00 a.m. Eastern Time.

Bid specifications can be obtained on the County's website www.gulfcounty-fl.gov or through the Gulf County Clerk's Office. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. All questions must be submitted to Clay Smallwood, P.E. at csmallwood@gulfcounty-fl.gov.

The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County.

BOARD OF COUNTY COMMISSIONERS

GULF COUNTY, FLORIDA

/s/ Sandy Quinn, Chairman

Publish Date: December 30, 2021

Publication Dates

Comments

No comments on this item Please log in to comment by clicking here